Commissioned By_______________________

Purchase Order Number___________________

Job Number____________________________

Primary Use:________________________________________________________________

Additional Uses:_____________________________________________________________

_________________________________________________________________

Number of Individual Screen Pages (if the page is a frame page, the number of frames per page):_____________________________________________________________________

Pixel Length Per Screen:__________Maximum Preferred:__________Minimum:__________

Any transfer of rights is conditional upon receipt of full payment.

1. Time for Payment
   Payment is due at each milestone upon the Client's acceptance of the Deliverables. All invoices are payable within thirty (30) days of receipt. A 1 1/2% monthly service charge is payable on all overdue balances. The grant of any license or right of copyright is conditioned on receipt of full payment.
2. Default in Payment
   The Client shall assume responsibility for all collection of legal fees necessitated by default in payment.
3. Estimates
   If this form is used for an estimate or assignment confirmation, the fees and expenses shown are minimum estimates only. Final fees and expenses shall be shown when invoice is rendered. The Client's approval shall be obtained for any increases in fees or expenses that exceed the original estimate by ten percent (10%) or more.
4. Expenses
   The Client shall reimburse the Developer for all expenses arising from this assignment, including the payment of any sales taxes due on this assignment, and shall advance $________to the Developer for payment of said expenses.
5. Internet Access
   Access to Internet will be provided by a separate Internet Service Provider (ISP) to be contracted by the Client and who will not be party to this agreement.
6. Progress Reports
   The Developer shall contact or meet with the Client on a mutually acceptable schedule to report all tasks completed, problems encountered, and recommended changes relating to the development and testing of the Website. The Developer shall inform the Client promptly by telephone upon discovery of any event or problem that may delay the development of the work significantly.
7. Developer's Guarantee for Program Use
   The Developer guarantees to notify the Client of any licensing and/or permissions required for art-generating/driving programs to be used.
8. Changes
   The Client shall be responsible for making additional payments for changes in original assignment requested by the Client. However, no additional payment shall be made for changes required to conform to the original assignment description. The Client shall offer the Developer the first opportunity to make any changes.
9. Testing and Acceptance Procedures
   The Developer will make every good faith effort to test all deliverables thoroughly and make all necessary corrections as a result of such testing prior to handing over the deliverables to the Client. Upon receipt of the deliverables, the Client shall either accept the deliverable and make the milestone payment set forth herein or provide the Developer with written notice of any corrections to be made and a suggested date for completion which should be mutually acceptable to both the Developer and the Client. The Developer shall designate _______________ (name) and the Client shall designate ________________(name) as the only designated persons who will send and accept all deliverables and receive and make all communications between the Developer and the Client. Neither party shall have any obligation to consider for approval or respond to materials submitted other than through the designated persons listed above. Each party has the right to change its designated person upon ______days(s) notice to the other.
10. Website Maintenance
    The Developer agrees to provide the Client with reasonable technical support and assistance to maintain and update the Website on the Internet during the Warranty Period of ________(dates) at no cost to the Client. Such assistance shall not exceed _________hours per calendar month. After the expiration of the Warranty Period the Developer agrees to provide the Client with reasonable technical support and assistance to maintain the update the Website on the Internet for an annual fee of $__________ for a period of _________year after the last day of the Warranty Period payable thirty (30) days prior to the commencement date of each year of the Maintenance Period. Such maintenance shall include correcting any errors or any failure of the Website to conform to the specifications. Maintenance shall not include the development of enhancements to the originally contracted project.
11. Enhancements
    Under the maintenance agreement, if the Client wishes to modify the Website, the Developer shall be given first option to provide a bid to perform such enhancements.
12. Confidential Information
    The Developer acknowledges and agrees that the source materials and technical and marketing plans or other sensitive business information, as specified by the Client, including all materials containing said information, which are supplied by the Client to the Developer or developed by the Developer in the course of developing the Website are to be considered confidential information. Information shall not be considered confidential if it is already publicly known through no act of the Developer.
13. Return of Source Information
    Upon the Client's acceptance of the Final Version, or upon the cancellation of the project, the Developer shall provide the Client with all copies and originals of the source materials provided to the Developer.
14. Ownership of Copyright
    Client acknowledges and agrees that Developer retains all rights to copyright in the subject material.
15. Ownership and Return of Artwork
    The Developer retains ownership of all original artwork, in any media,, including digital files, whether preliminary or final. The Client waives the right to challenge the validity of the Developer's ownership of the art subject to this agreement because of any change or evolution of the law and will return all artwork within thirty (30) days of use.
16. Cancellation
    In the event of cancellation of this assignment, ownership of all copyrights and any original artwork shall be retained by the Developer, and a cancellation fee for work completed, based on the prorated portion of the next payment and expenses already incurred, shall be paid by the Client.
17. Copy-Protection
    The Client must copy-protect all final art which is the subject of this agreement against duplication or alteration.
18. Credit Lines
    The Developer shall be given credit on: (a) floppy disk, (b) documentation, (c) packaging, (d) Developer's mark on art.
    _______ If this is checked, the Developer shall receive copyright notice in this form:
    200__ __________________________.
19. Alterations
    Any electronic alteration of original art (color shift, mirroring, flopping, combination cut and paste, deletion) creating additional art is prohibited without the express permission of the developer. The Developer will be given first opportunity to make any alterations required. Unauthorized alterations shall constitute additional use and will be billed accordingly.
20. Other Operating Systems Conversions
    The Developer shall be given first option at compiling the work for operating systems beyond the original use.
21. Unauthorized Use and Program Licenses
    The Client will indemnify the Developer against all claims and expenses arising from uses for which the Client does not have rights to or authority to use. The Client will be responsible for payment of any special licensing or royalty fees resulting from the use of graphics programs that require such payments.
22. Warranty of Originality
    The Developer warrants and represents that, to the best of his/her knowledge, the work assigned hereunder is original and has not been previously published, or that consent to use has been obtained on an unlimited basis; that all work or portions thereof obtained through the undersigned from third parties is original or, if previously published, that consent to use has been obtained on an unlimited basis; that the Developer has full authority to make this agreement; and that the work prepared by the Developer does not contain any scandalous, libelous, or unlawful matter. This warranty does not extend to any uses that the Client or others may make of the Developer's product which may infringe on the rights of others. CLIENT EXPRESSLY AGREES THAT IT WILL HOLD THE DEVELOPER HARMLESS FOR ALL LIABILITY CAUSED BY THE CLIENT'S USE OF THE DEVELOPER'S PRODUCT TO THE EXTENT SUCH USE INFRINGES ON THE RIGHTS OF OTHERS.
23. Limitation of Liability
    Client agrees that it shall not hold the Developer or his/her agents or employees liable for any incidental or consequential damages which arise from the Developer's failure to perform any aspect of the Project in a timely manner, regardless of whether such failure was caused by intentional or negligent acts or omissions of the Developer or a third party. Furthermore, the Developer disclaims all implied warranties, including the warranty of merchantability and fitness for a particular use.
24. Dispute Resolution
    Any disputes in excess of $_________ (maximum limit for small claims court) arising out of this Agreement shall be submitted to binding arbitration before the Joint Ethics Committee or a mutually agreed upon arbitrator pursuant to the rules of the American Arbitration Association. The Arbitrator's award shall be final, and judgment may be entered in any court having jurisdiction thereof. The Client shall pay all arbitration and court costs, reasonable attorney's fees, and legal interest on any award of judgment in favor of the Developer.
25. Acceptance of Terms
    The signature of both parties shall evidence acceptance of these terms.

date________________________________________

developer's signature __________________________________________________________

authorized signature __________________________________________________________

client's name and title _________________________________________________________